• Recordar
  • Enviar
  • Imprimir
93959 de 100107
  • Dumfries
  • 14.09.2006
  • Convocatoria
  • (concurso 5998)

Installation of MRI (Magnetic Resinance Imaging) Scanner at Dumfries and Galloway Royal Infirmary, New MRI suite

Anuncio


 
  • Datos del proyecto

    maximizar

    Cierre de solicitudes 14.09.2006, 12:00 Cierre de solicitudes
    Procedimiento Procedimiento negociado
    Autorizados a participar Arquitectos (superiores/técnicos), Ingenieros constructores
    Tipo de edificación Sistema de salud
    Idioma Inglés
    Tarea
    The Board seeks to appoint an architect to design and administer the procurement of and lead the design team for a new MRI suite within Dumfries and Galloway Royal Infirmary, Dumfries, with an estimated capital construction cost of 750 000 GBP. The architect is to employ or engage as subcontractors, such civil and structural engineers, mechanical and electrical services engineers, quantity surveyors, planning supervisors and other specialist consultants as necessary. The construction contract will be let by the Board. It will be administered, and the works inspected by the architect with the support of his subcontractors. The project consists of alterations and adaptations to an existing area within Dumfries and Galloway Royal Infirmary to accommodate the MRI suite. The accommodation is planned to include scanner room, technical equipment room, control room, in-patient and out-patient waiting areas, patient changing, general store, toilet accommodation, reception/office accommodation.
    Dirección del proyecto Dumfries

  • Texto de la convocatoria de la licitación

    maximizar

    • UK-Dumfries: architectural and related services

      2006/S 153-165676

      CONTRACT NOTICE

      Services


      SECTION I: CONTRACTING AUTHORITY

       I.1) NAME, ADDRESSES AND CONTACT POINT(S):  
      Dumfries and Galloway Health Board, Operations Directorate, Crichton Hall, Crichton Royal Hospital, Contact: James McCambley, Attn: James McCambley, UK-Dumfries DG1 4TG. Tel.  01387 244199. E-mail: james.mccambley@nhs.net. Fax  01387 244211.
      Further information can be obtained at: As in above-mentioned contact point(s).
      Specifications and additional documents (including documents for competitive dialogue and a dynamic purchasing system) can be obtained at: As in above-mentioned contact point(s).
      Tenders or requests to participate must be sent to: As in above-mentioned contact point(s).
       I.2) TYPE OF THE CONTRACTING AUTHORITY AND MAIN ACTIVITY OR ACTIVITIES:  
      Body governed by public law.
      Health.
      The contracting authority is purchasing on behalf of other contracting authorities: no.

      SECTION II: OBJECT OF THE CONTRACT

       II.1) DESCRIPTION
       II.1.1) Title attributed to the contract by the contracting authority:  
      Design Team Services for Installation of MRI (Magnetic Resinance Imaging) Scanner at Dumfries and Galloway Royal Infirmary, UK-Dumfries.
       II.1.2) Type of contract and location of works, place of delivery or of performance:  
      Services.
      Service category: No 12.
      Main place of performance: Various in NHS Scotland.
      Dumfries and Galloway Royal Infirmary Dumfries.
      NUTS code: UKM32.
       II.1.3) The notice involves:  
      A public contract.
       II.1.4) Information on framework agreement:
       II.1.5) Short description of the contract or purchase(s):  
      The Board seeks to appoint an architect to design and administer the procurement of and lead the design team for a new MRI suite within Dumfries and Galloway Royal Infirmary, Dumfries, with an estimated capital construction cost of 750 000 GBP. The architect is to employ or engage as subcontractors, such civil and structural engineers, mechanical and electrical services engineers, quantity surveyors, planning supervisors and other specialist consultants as necessary. The construction contract will be let by the Board. It will be administered, and the works inspected by the architect with the support of his subcontractors. The project consists of alterations and adaptations to an existing area within Dumfries and Galloway Royal Infirmary to accommodate the MRI suite. The accommodation is planned to include scanner room, technical equipment room, control room, in-patient and out-patient waiting areas, patient changing, general store, toilet accommodation, reception/office accommodation.
       II.1.6) Common procurement vocabulary (CPV):  
      74220000, 74222000, 74224000, 74225000.
       II.1.7) Contract covered by the Government Procurement Agreement (GPA):  
      Yes.
       II.1.8) Division into lots:  
      No.
       II.1.9) Variants will be accepted:  
      No.
       II.2) QUANTITY OR SCOPE OF THE CONTRACT
       II.2.1) Total quantity or scope:
       II.2.2) Options:
       II.3) DURATION OF THE CONTRACT OR TIME-LIMIT FOR COMPLETION:

      SECTION III: LEGAL, ECONOMIC, FINANCIAL AND TECHNICAL INFORMATION

       III.1) CONDITIONS RELATING TO THE CONTRACT
       III.1.1) Deposits and guarantees required:  
      Appropriate professional indemnity insurances from the Architect and subcontractors and design warranties from subcontractors will be required.
       III.1.2) Main financing conditions and payment arrangements and/or reference to the relevant provisions regulating them:
       III.1.3) Legal form to be taken by the group of economic operators to whom the contract is to be awarded:  
      Prime contractor.
       III.1.4) Other particular conditions to which the performance of the contract is subject:
       III.2) CONDITIONS FOR PARTICIPATION
       III.2.1) Personal situation of economic operators, including requirements relating to enrolment on professional or trade registers:  
      Information and formalities necessary for evaluating if requirements are met: Persons wishing to tender should apply for the stage 1 questionnaire from the address in I.1 and return it fully completed to the address in I.1 by 12:00 on 14.9.2006.
       III.2.2) Economic and financial capacity:
       III.2.3) Technical capacity:
       III.2.4) Reserved contracts:
       III.3) CONDITIONS SPECIFIC TO SERVICES CONTRACTS
       III.3.1) Execution of the service is reserved to a particular profession:  
      Yes.
      Architects must either be registered with the Architect’s Registration Board or hold such qualifications as comply with Articles 3 and 4 of EC Directive 85/384/EEC. The Architect and each subcontractor shall be a member of a professional body appropriate to the professional service to be undertaken.
       III.3.2) Legal entities should indicate the names and professional qualifications of the staff responsible for the execution of the service:  
      Yes.

      SECTION IV: PROCEDURE

       IV.1) TYPE OF PROCEDURE
       IV.1.1) Type of procedure:  
      Restricted.
       IV.1.2) Limitations on the number of operators who will be invited to tender or to participate:  
      Envisaged minimum number: 5. Maximum number: 6
      Objective criteria for choosing the limited number of candidates: As specified in Stage 1 questionnaire.
       IV.1.3) Reduction of the number of operators during the negotiation or dialogue:
       IV.2) AWARD CRITERIA
       IV.2.1) Award criteria:  
      The most economically advantageous tender in terms of the criteria stated in the specifications, in the invitation to tender or to negotiate or in the descriptive document.
       IV.2.2) An electronic auction will be used:  
      No.
       IV.3) ADMINISTRATIVE INFORMATION
       IV.3.1) File reference number attributed by the contracting authority:
       IV.3.2) Previous publication(s) concerning the same contract:
       IV.3.3) Conditions for obtaining specifications and additional documents or descriptive document
       IV.3.4) Time-limit for receipt of tenders or requests to participate:  
      14.9.2006 - 12:00.
       IV.3.5) Date of dispatch of invitations to tender or to participate to selected candidates:
       IV.3.6) Language(s) in which tenders or requests to participate may be drawn up:  
      English.
       IV.3.7) Minimum time frame during which the tenderer must maintain the tender:
       IV.3.8) Conditions for opening tenders:

      SECTION VI: COMPLEMENTARY INFORMATION

       VI.1) THIS IS A RECURRENT PROCUREMENT:  
      No.
       VI.2) CONTRACT RELATED TO A PROJECT AND/OR PROGRAMME FINANCED BY EU FUNDS:  
      No.
       VI.3) ADDITIONAL INFORMATION:  
      II.3. Duration of the contract or time-limit for completion: completion: 6.7.2007.
      The authority will incorporate a standstill period of a minimum of 11 calendar days at the point information on the award of the contract is communicated to tenderers. This period allows unsuccessful tenderers to seek further defriefing from the contracting authority before the contract is entered into. Applicants have two working days from notification of the award decision to request additional debriefing and that information will be provided a minimum of 3 working days before expiry of the standstill period. Such additional information should be requested from the address in point I.1.
      If an appeal regarding the award of a contract has not been successfully resolved the Public Contracts (Scotland) Regulations 2006 provide for aggrieved parties who have been harmed or are at risk of harm by a breach of the rules to take action in a court of competent jurisdiction. Any such action must be brought promptly (generally within 3 months). Where a contract has not been entered into the court may order the settling aside of the award decision or order the authority to amend any document and may award damages. If the contract has been entered into the court may only award damages.
       VI.4) PROCEDURES FOR APPEAL
       VI.4.1) Body responsible for appeal procedures:
       VI.4.2) Lodging of appeals:
       VI.4.3) Service from which information about the lodging of appeals may be obtained:
       VI.5) DATE OF DISPATCH OF THIS NOTICE:  
      7.8.2006.
  • Tarjeta

    maximizar

  • Garantía

    Competitionline no asume ninguna responsabilidad por errores, omisiones, interrupciones, borrados, faltas o retrasos en la operación o en la transmisión de contenidos. competitionline no asume ninguna responsabilidad por pérdidas o daños que resulten de la utilización de las páginas de Internet, del uso de los contenidos de los usuarios o de los contenidos de terceras personas, que provengan de las páginas de Internet o que hayan sido publicados a través del servicio y sean transferidos a los usuarios, o de las interacciones entre los usuarios y las páginas de Internet (en línea y fuera de línea). Por favor, lea al respecto nuestras Condiciones de Uso.

Inicio de página
Anuncio