United Kingdom-London: Asbestos removal services
2018/S 106-241816
Contract notice
Services
Section I: Contracting authority
Town Hall, Wandsworth High Street
London
SW18 2PU
United Kingdom
Contact person: Ishmam Choudhury
Telephone: +44 2088715021
E-mail: MjE5VlBVXGJRVWJfZi1kTltRYGRcX2FVG1RcYxtiWA==
NUTS code: UKI34
Internet address(es):
Main address: https://www.delta-esourcing.com
Address of the buyer profile: http://www.wandsworth.gov.uk/
Civic Centre, 44 York Street
Twickenham
TW1 3BZ
United Kingdom
Contact person: Ishmam Choudhury
Telephone: +44 2088715021
E-mail: MjE0W2VaX1NfIFVaYWdWWmdkazJkW1VaX2FgVlNgVmlTYFZlaWFkZlogWWFoIGdd
NUTS code: UKI75
Internet address(es):
Main address: https://www.delta-esourcing.com
Address of the buyer profile: www.richmond.gov.uk
Section II: Object
The Provision of Asbestos Survey and Sampling Services
Both Richmond and Wandsworth Councils are seeking to appoint two asbestos specialist consultants to undertake Asbestos Sampling and Removal Services. The contract is expected to have a duration of 5 years with the option to extend for a period or periods of up to 2 years at the absolute discretion of the Councils. The estimated total value of the contract is 1 722 000 GBP.
Following receipt of tenders, it is envisaged that 2 contractors will be appointed, acting as primary and secondary contractors. It is proposed that 60 % of the work will be allocated to the primary Contractor and 40 % to the secondary to ensure a contractor is always available to carry out the service.
To ensure quality of service, Tenderers will need to satisfy the Council that they are able to ensure swiftness in service provision.
The successful Tenderer must undertake all preparatory work and must commence full operations under the contract on the commencement date.
The Provision of Asbestos Survey and Sampling Services
Wandsworth,Hounslow and Richmond upon Thames.
Both Richmond and Wandsworth Councils are seeking to appoint two asbestos specialist consultants to undertake Asbestos Sampling and Removal Services. The contract is expected to have a duration of 5 years with the option to extend for a period or periods of up to 2 years at the absolute discretion of the Councils. The estimated total value of the contract is 1 033 200 GBP. Due to the nature of the initial surveys and the need to allow necessary works to proceed without delay, it is anticipated that the service will commence immediately. Asbestos surveys are required for all public buildings together with the communal areas of the Councils residential housing stock. The service shall also take place in domestic properties within the 2 Boroughs.
Following receipt of tenders, it is envisaged that 2 contractors will be appointed, acting as primary and secondary contractors. It is proposed that the winning Bidder for this lot will be allocated 60 % of the services and will be classified as the primary Contractor.
To ensure quality of service, Tenderers will need to satisfy the Council that they are able to ensure swiftness in service provision.
The proposed contract period is five (5) years commencing on 3.9.2018 and is subject to an extension or extensions of up to an aggregate of two (2) years at the absolute discretion of the Authorities.
To access Lot 2 documents, please use the following link: https://www.delta-esourcing.com/respond/79474U67TV
The Provision of Asbestos Survey and Sampling Services
Wandsworth,Hounslow and Richmond upon Thames.
Both Richmond and Wandsworth Councils are seeking to appoint 2 asbestos specialist consultants to undertake Asbestos Sampling and Removal Services. The contract is expected to have a duration of 5 years with the option to extend for a period or periods of up to 2 years at the absolute discretion of the Councils. The estimated total value of the contract is 688 800 GBP. Due to the nature of the initial surveys and the need to allow necessary works to proceed without delay, it is anticipated that the service will commence immediately. Asbestos surveys are required for all public buildings together with the communal areas of the Councils residential housing stock. The service shall also take place in domestic properties within the two Boroughs.
Following receipt of tenders, it is envisaged that 2 Suppliers will be awarded the contract, acting as primary and secondary contractors. It is proposed that the winning Bidder for this lot will be allocated 40 % of the services and will be classified as the secondary Contractor.
To ensure quality of service, Tenderers will need to satisfy the Council that they are able to ensure swiftness in service provision.
The proposed contract period is five (5) years commencing on 3.9.2018 and is subject to an extension or extensions of up to an aggregate of two (2) years at the absolute discretion of the Authorities.
To access Lot 2 documents, please use the following link: https://www.delta-esourcing.com/respond/79474U67TV
Section III: Legal, economic, financial and technical information
See Procurement documents.
Section IV: Procedure
Wandsworth Borough Council.
Section VI: Complementary information
The contracting authority considers that this contract may be suitable for economic operators that are small or medium enterprises (SMEs). However, any selection of tenderers will be based solely on the criteria set out for the procurement.
For more information about this opportunity, please visit the Delta eSourcing portal at:
https://www.delta-esourcing.com/tenders/UK-UK-London:-Asbestos-removal-services./A5R7335U98
To respond to this opportunity, please click here:
https://www.delta-esourcing.com/respond/A5R7335U98
GO Reference: GO-201864-PRO-12549658.
The Strand
WC2A 2LL
United Kingdom
Telephone: +44 2079476000
70 Whitehall
London
SW1 2AS
United Kingdom
Internet address: https://www.gov.uk/government/organisations/cabinet-office
The councils will incorporate a minimum 10 calendar days standstill period at the point information on the award of the contracts is communicated to Tenderers. Applicants who are unsuccessful shall be informed by the buyer as soon as possible after the decision has been made as to the reasons why the applicant was unsuccessful. If an appeal regarding the award of the contract has not been successfully resolved, the public contracts Regulations 2015 (SI 2015 no 102) provide for aggrieved parties who have been harmed or are at risk of harm by breach of the rules to take legal action. Any such action must be brought within the applicable limitation period. Where a contract has not been entered into, the court may order the setting aside of the award decision or order the buyer to amend any document and may award damages. If the contract has been entered into the Court may, depending on the circumstances, award damages, make a declaration of ineffectiveness, order the relevant buyer to pay a fine, and /or order that the duration of the contract be shortened. The purpose of the standstill period referred to above is to allow the parties to apply to the Courts to set aside the award decision before the contract is entered into.