loading
  • GB-NE1 4AX Newcastle Upon Tyne
  • 17.09.2018
  • Ausschreibung
  • (ID 2-312492)

NEX18/32 Howdon Satellite Depot Facility

 
  • Projektdaten

    maximieren

    Bewerbungsschluss 17.09.2018, 12:00 Bewerbungsschluss
    Verfahren Nicht offenes Verfahren
    Teilnehmer Gewünschte Teilnehmerzahl: max. 6
    Gebäudetyp Verkehr
    Art der Leistung Bauleistung / Objektplanung Verkehrsanlagen
    Sprache Englisch
    Aufgabe
    As part of the Metro Futures programme, Nexus wishes to; procure a new fleet of Electric Multiple Units to replace its existing Metrocar fleet, procure a maintainer for the New and Existing Fleets, and procure New Maintenance facilities. In order to enable sufficient capacity at the current Depot site in Gosforth, a new temporary Satellite Depot Facility is required, which is the remit for these works.
    Leistungsumfang
    The Satellite Depot Facility works are located on a site adjacent to the existing Metro System rail corridor between Howdon and Percy Main Stations. The existing site shall be cleared as part of the works.
    The new Satellite Depot facility shall seek to accommodate a minimum of 10no. 65m length trains, for stabling. The stabling roads shall be separated to allow for cleaning access and full visual inspection for the trains prior to service. They shall also be provided with power points for cleaning staff.
    A delivery track is required to enable delivery of the new fleet of rolling stock via road vehicle delivery. This shall be used for the delivery and recovery of trains and shall not affect the remainder of the site operations when in use.
    A building for single vehicle light maintenance and new rolling stock delivery/assembly shall be provided with a pit and flexible high-level train access. Nexus aspiration would be that the site enabled the Metrocars to access the building without a move onto the main network.
    The broad scope of works comprises as follows:
    — Outline Design and Detailed Design of the Satellite Depot Facility,
    — Mobilisation to site,
    — Site preparation and enabling,
    — Site perimeter security fencing,
    — Install tracks and ballast over the extents of the works,
    — Install new rail connection to the existing Metro rail system,
    — Modify existing highway access for articulated vehicles,
    — Install bottom ballast,
    — Install OLE and associated OLE Masts, including connection to the existing Metro rail system,
    — Provide a traction supply sub-station/transformer facility,
    — Construct a Satellite Depot Facility building with suitable staff accommodation,
    — nstall signalling compatible with the main network,
    — Install a Depot Protection System.
    Adresse des Bauherren UK-NE1 4AX Newcastle Upon Tyne
    TED Dokumenten-Nr. 365602-2018

  • Anzeigentext Ausschreibung

    maximieren


    • United Kingdom-Newcastle Upon Tyne: Railway depot construction work

      2018/S 159-365602

      Contract notice – utilities

      Works

      Legal Basis:

      Directive 2014/25/EU

      Section I: Contracting entity

      I.1)Name and addresses
      Nexus
      Nexus House, St James Boulevard
      Newcastle Upon Tyne
      NE1 4AX
      United Kingdom
      Contact person: Mr Paul Fergus
      Telephone: +44 1912033160
      E-mail: MjEyaFliWFlmZzRiWWxpZyJjZlsiaV8=
      NUTS code: UKC2

      Internet address(es):

      Main address: http://www.nepo.org

      Address of the buyer profile: http://www.nexus.org.uk

      I.2)Information about joint procurement
      I.3)Communication
      The procurement documents are available for unrestricted and full direct access, free of charge, at: www.nepo.org
      Additional information can be obtained from the abovementioned address
      Tenders or requests to participate must be submitted electronically via: http://www.nepo.org
      I.6)Main activity
      Urban railway, tramway, trolleybus or bus services

      Section II: Object

      II.1)Scope of the procurement
      II.1.1)Title:

      NEX18/32 Howdon Satellite Depot Facility

      Reference number: DN349262
      II.1.2)Main CPV code
      45234112
      II.1.3)Type of contract
      Works
      II.1.4)Short description:

      As part of the Metro Futures programme, Nexus wishes to; procure a new fleet of Electric Multiple Units to replace its existing Metrocar fleet, procure a maintainer for the New and Existing Fleets, and procure New Maintenance facilities. In order to enable sufficient capacity at the current Depot site in Gosforth, a new temporary Satellite Depot Facility is required, which is the remit for these works.

      II.1.5)Estimated total value
      Value excluding VAT: 10 000 000.00 GBP
      II.1.6)Information about lots
      This contract is divided into lots: no
      II.2)Description
      II.2.1)Title:
      II.2.2)Additional CPV code(s)
      34632000
      42965110
      45213260
      45213352
      45234100
      45234115
      71311230
      II.2.3)Place of performance
      NUTS code: UKC2
      II.2.4)Description of the procurement:

      The Satellite Depot Facility works are located on a site adjacent to the existing Metro System rail corridor between Howdon and Percy Main Stations. The existing site shall be cleared as part of the works.

      The new Satellite Depot facility shall seek to accommodate a minimum of 10no. 65m length trains, for stabling. The stabling roads shall be separated to allow for cleaning access and full visual inspection for the trains prior to service. They shall also be provided with power points for cleaning staff.

      A delivery track is required to enable delivery of the new fleet of rolling stock via road vehicle delivery. This shall be used for the delivery and recovery of trains and shall not affect the remainder of the site operations when in use.

      A building for single vehicle light maintenance and new rolling stock delivery/assembly shall be provided with a pit and flexible high-level train access. Nexus aspiration would be that the site enabled the Metrocars to access the building without a move onto the main network.

      The broad scope of works comprises as follows:

      — Outline Design and Detailed Design of the Satellite Depot Facility,

      — Mobilisation to site,

      — Site preparation and enabling,

      — Site perimeter security fencing,

      — Install tracks and ballast over the extents of the works,

      — Install new rail connection to the existing Metro rail system,

      — Modify existing highway access for articulated vehicles,

      — Install bottom ballast,

      — Install OLE and associated OLE Masts, including connection to the existing Metro rail system,

      — Provide a traction supply sub-station/transformer facility,

      — Construct a Satellite Depot Facility building with suitable staff accommodation,

      — nstall signalling compatible with the main network,

      — Install a Depot Protection System.

      II.2.5)Award criteria
      Price is not the only award criterion and all criteria are stated only in the procurement documents
      II.2.6)Estimated value
      II.2.7)Duration of the contract, framework agreement or dynamic purchasing system
      Duration in months: 16
      This contract is subject to renewal: no
      II.2.9)Information about the limits on the number of candidates to be invited
      Maximum number: 6
      II.2.10)Information about variants
      Variants will be accepted: no
      II.2.11)Information about options
      Options: no
      II.2.12)Information about electronic catalogues
      II.2.13)Information about European Union funds
      The procurement is related to a project and/or programme financed by European Union funds: no
      II.2.14)Additional information

      Section III: Legal, economic, financial and technical information

      III.1)Conditions for participation
      III.1.1)Suitability to pursue the professional activity, including requirements relating to enrolment on professional or trade registers
      III.1.2)Economic and financial standing
      III.1.3)Technical and professional ability
      III.1.4)Objective rules and criteria for participation
      III.1.5)Information about reserved contracts
      III.1.6)Deposits and guarantees required:
      III.1.7)Main financing conditions and payment arrangements and/or reference to the relevant provisions governing them:
      III.1.8)Legal form to be taken by the group of economic operators to whom the contract is to be awarded:
      III.2)Conditions related to the contract
      III.2.2)Contract performance conditions:
      III.2.3)Information about staff responsible for the performance of the contract

      Section IV: Procedure

      IV.1)Description
      IV.1.1)Type of procedure
      Restricted procedure
      IV.1.3)Information about a framework agreement or a dynamic purchasing system
      IV.1.4)Information about reduction of the number of solutions or tenders during negotiation or dialogue
      IV.1.6)Information about electronic auction
      IV.1.8)Information about the Government Procurement Agreement (GPA)
      The procurement is covered by the Government Procurement Agreement: yes
      IV.2)Administrative information
      IV.2.1)Previous publication concerning this procedure
      Notice number in the OJ S: 2018/S 136-311608
      IV.2.2)Time limit for receipt of tenders or requests to participate
      Date: 17/09/2018
      Local time: 12:00
      IV.2.3)Estimated date of dispatch of invitations to tender or to participate to selected candidates
      IV.2.4)Languages in which tenders or requests to participate may be submitted:
      English
      IV.2.6)Minimum time frame during which the tenderer must maintain the tender
      IV.2.7)Conditions for opening of tenders

      Section VI: Complementary information

      VI.1)Information about recurrence
      This is a recurrent procurement: no
      VI.2)Information about electronic workflows
      VI.3)Additional information:
      VI.4)Procedures for review
      VI.4.1)Review body
      Nexus
      Nexus House, St James' Boulevard
      Newcastle upon Tyne
      NE1 4AX
      United Kingdom
      Telephone: +44 1912033446
      E-mail: MjE3Y1RdU1RhYi9dVGdkYh1eYVYdZFo=

      Internet address: http://www.nexus.org.uk

      VI.4.2)Body responsible for mediation procedures
      Royal Courts of Justice
      The Strand
      London
      WC2A 2LL
      United Kingdom
      Telephone: +44 2079476000
      VI.4.3)Review procedure
      Precise information on deadline(s) for review procedures:

      Precise information on deadline(s) for review procedures:

      Nexus will incorporate a minimum 10 calendar day standstill period at the point information on the

      Award of the contracts is communicated to tenderers. If an appeal regarding the award of the contract has not been successfully resolved by Nexus, the Utilities Contracts Regulations 2016 (SI 2016 No. 274) provide for aggrieved parties who have been harmed or are at risk of harm by breach of the rules to take action in the High Court (England, Wales, and Northern Ireland).Any such action must be brought promptly (generally within three months). If a declaration of ineffectiveness is sought, any such action must be brought within 30 days where Nexus has communicated the award of the contract and a summary of reasons to tenderers, or otherwise within 6 months of the contracts being entered into. Where a contract has not been entered into, the Court may order the setting aside of the award decision or order Nexus to amend any document and may award damages. If the contract has been entered into the Court may, depending on the circumstances, award damages, make a declaration of ineffectiveness, order Nexus to pay a fine, and/or order that the duration of the contract be shortened. The purpose of the standstill period referred to above is to allow the parties to apply to the Courts to set aside the award decision before the contract is entered into.

      VI.4.4)Service from which information about the review procedure may be obtained
      VI.5)Date of dispatch of this notice:
      17/08/2018
    © European Union, http://ted.europa.eu
    • Protected by Copyscape

  • Gewährleistung

    competitionline übernimmt keine Verantwortung für Fehler, Auslassungen, Unterbrechungen, Löschungen, Mängel oder Verzögerungen im Betrieb oder bei Übertragung von Inhalten. competitionline übernimmt keine Verantwortung für Einbußen oder Schäden, die aus der Verwendung der Internetseiten, aus der Verwendung von Nutzerinhalten oder von Inhalten Dritter, die aus den Internetseiten oder über den Service gepostet oder an Nutzer übertragen werden, oder aus Interaktionen zwischen Nutzer und Internetseiten (online oder offline) resultieren. Bitte lesen Sie hierzu unsere Nutzungsbedingungen.

INFO-BOX

Ausschreibung veröffentlicht 21.08.2018
Zuletzt aktualisiert 21.08.2018
Wettbewerbs-ID 2-312492 Status Kostenpflichtig
Seitenaufrufe 32

Seitenanfang